Nevada Conditional Waiver and Release upon Progress Payment

Provided under NRS 108.2457(5)(a), this waiver offers the most protection for lien claimants, because it states that if the claimant(s) have actually been paid to date (including no returned or stopped payment checks) the waiver serves as effective proof against any lien claim on the property. The lien is "conditioned" on receiving payment and is only waived if the claimant actually receives the payment.

By filing the form, the lien claimant represents that he or she either has already paid or will use the money he or she receives from this progress payment in order to make prompt payment in full all his or her laborers, subcontractors, materialmen and suppliers for all work, materials or equipment that are the subject of this waiver and release.

Getting a lien waiver also allows property owners to shield the title to their property from the general contractor, material supplier and every subcontractor involved with a project. By releasing the lien upon a progress payment, the property owner once again has clear title and can obtain financing or sell the property.

The property owner should require lien and labor waivers to be submitted with the contractor's invoices and no payment of any invoice should be made unless properly signed lien and labor waivers are provided. Proper lien waivers can protect the property owner from liens filed by the contractor's subcontractors, suppliers and laborers who might record a lien if they are not paid by the contractor.

Each case is unique, so contact an attorney with specific questions or for complex situations.

How to Use This Form

Select your county or independent city from the list above
Download the county or independent city-specific form
Fill in the required information
Have the document notarized if required
Record with your county or independent city recorder's office

What Others Like You Are Saying

— curtice c.

"I bought the Transfer on Death Deed documents. Great product and the accompanying example and guides…"

— Mary S.

"Wonderful!! So easy to locate the file you need and printing is a snap!! Thank you so much for this …"

— silvia m.

"Used the forms for a quitclaim deed. Worked great! Also, big bonus to have the extra forms available…"

— ROBERT K.

"It was so easy to obtain the necessary documents."

— Lisa J.

"I ordered a Lis Pendens form and it was exactly what I needed. Saved me a lot of time since I am sel…"

Common Uses for Conditional Waiver upon Progress

Protect a contractor's right to payment for work performed
Establish priority of a construction lien on a property
Protect a supplier's right to payment for delivered materials
Protect payment rights for electrical, plumbing, or HVAC work
Establish a legal claim against property for unpaid labor
Secure payment for materials supplied to a construction project
Notify a general contractor of unpaid subcontractor invoices

Compare other Nevada deed forms and documents

Quitclaim Deed Gift Deed Warranty Deed Special Warranty Deed Grant Deed Easement Deed Termination of Easement Correction Deed Mineral Deed Mineral Quitclaim Deed Transfer on Death Deed Transfer on Death Revocation Transfer on Death Affidavit Special Power of Attorney for Real Property Affidavit of Death of Joint Tenant Affidavit of Death of Spouse Holding Community Property Personal Representative Deed of Distribution Personal Representative Deed of Sale Disclaimer of Interest Certificate of Trust Deed of Trust Assignment of Deed of Trust Deed of Full Reconveyance Substitution of Trustee and Deed of Reconveyance (For Deed of Trust) Contract of Sale Memorandum of Contract of Sale Release of Memorandum of Contract of Sale Notice of Right to Lien Notice of Mechanics Lien Notice of Completion Discharge of Lien Release of Notice of Lien by Surety Bond Release of Prospective Lien by Surety Bond Unconditional Waiver upon Progress Unconditional Final Waiver of Lien Conditional Final Waiver of Lien Lis Pendens Lis Pendens Release

Important: County or Independent City-Specific Forms

Our conditional waiver upon progress forms are specifically formatted for each county or independent city in Nevada.

After selecting your county or independent city, you'll receive forms that meet all local recording requirements, ensuring your documents will be accepted without delays or rejection fees.

Back to Nevada Forms